Article Index
Twitter Posts
« Construction Schedules & Delay Claims - General Contractor Claims | Main | DiNicola Addresses BC Law Students on Construction Law Careers »
Friday
Dec162011

Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates

This is the first in a series of articles on Construction Schedules and Delay Claims.  This article addresses (1) schedule uses; (2) schedule importance; and (3) schedule updates.

I.  Schedule Uses.

The Schedule has several uses.  The Baseline Schedule explains how the contractor is going to build the project.  The Schedule also aids in subcontractor management.  It is an important tool for both general contractors and subcontractors for coordination of activities.  Schedule Updates allows the parties to graphically determine progress when compared to the Baseline Schedule.  A proper Schedule also depicts changes in scope and the effect on the Schedule.  Schedules are obviously used for claim prosecution and claim defense.

II.  Why is the Schedule Important.

All construction contracts should have two basic elements in the scope of work.  The first element of the scope of work is the labor and materials to construct the building.  The second element of the scope of work is to construct the building within a stated amount of time.  A delay in the schedule is a breach of the contract -- for the Owner, for the contractor, for the subcontractors.

Delay claims are difficult to prove because there are so many variables, so many different entities involved, a lot of educated guesses, and great expense (lawyers and experts).  However, these claims serve practical purposes, aside from litigation and arbitration of these claims:         

  • Negotiation at project close-out with owner.  Often, the final payment is the most difficult payment to receive.  At that time, general contractors may receive numerous backcharges from the owner against the final contract balance.  Even if some of those claims are legitimate, a well documented and noticed delay claim can be used to negotiate a final close-out that is acceptable, even if the general contractor does not receive delay damages.
  • Negotiation at project close-out with subcontractors.  Some subcontractors routinely submit delay or inefficiency claims, using so-called industry data to support the claim.  Using the subcontract and the schedule during the project to notice the subcontractor of its schedule delays will assist in a timely project close-out.  Additionally, when faced with a troubled project from a schedule standpoint, the contractor must, during the project, be able to document specific delaying events and impacts for each subcontractor.

III.  Schedule Updates.

Periodic Schedule Updates serve several uses:

  • They keep all parties (owner, contractor, subcontractor) up to date on the progress and what needs to occur to remain on schedule (or to catch up on the schedule)
  • They serve as a control for the contractor.  The Schedule Update shows the contractor where it is on the schedule, where it can pick up time, where and who is falling behind schedule. 
  • Schedule Updates can also serve as a cost control mechanism.  If the project is falling behind schedule and that is depicted on the schedule updates, the contractor knows that it will incur additional expense either (1) through extended general conditions; or (2) acceleration payments to subcontractors.  Often, without proper updating, the contractor will fall behind schedule, start paying subcontractors for overtime to accelerate, but not know (1) who is responsible; or (2) how much it will cost.  More often than not, it is too late when the costs are realized.                    

Schedule Updates generally show one of three things:  (1) on schedule; (2) behind schedule; or (3) ahead of schedule.  As a result, distribution of schedule updates can be a sensitive issue.  As an initial matter, the general contractor must review the contract requirements.  Many contracts require that periodic schedule updates be published to the owner.  In these instances, the schedule updates must be drafted with care.  It is never wise to ignore bad facts or bad news regarding the schedule until the end of the project.  However, it is also not good practice to overload the owner with information that consists mostly of projections.  A reasonable way to approach schedule updates that are distributed to the owner is to provide summary schedule updates (if allowed by the contract).  If the summary shows a delay, then the general contractor should be prepared to discuss (1) the reasons for the delay; and (2) possible solutions to mitigate the delay.

For additional information, please contact Jack DiNicola at DSU.

 

References (194)

References allow you to track sources for this article, as well as articles that were written in response to this article.
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: learn about
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: Arthur Falcone
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: Phil St Ores
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: Arthur Falcone
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: .VBidwEunDfM
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: Arthur Falcone
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: realtors
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: agen bola
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: glutax
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: glutax
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: agen bola
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: Ebon Talifarro
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: Eric Gonchar
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: epic island cheats
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: epic island cheats
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: microcreditos
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: globalbola
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: pulse8.com
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: go to the website
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: Karl Jobst
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: Tonye Cole
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: wett-bonus
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: freebets
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: wettfreunde
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: sportwetten
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: seo toronto
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: Suggested Site
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: full article
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: coupons groceries
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: webpage
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: rem cua
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    They serve as a control for the builder. The Schedule Update demonstrates the builder where it is on the calendar, where it can get time, where and who is falling behind timetable.
  • Response
    Response: More Bonuses
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: game beta
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: x8 energy gum
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: Savile Row
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: black ops 3 cd key
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: sn.im
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: Keval
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: besi wiremesh
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: home insurance nc
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: cxvx
    cxv
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: cure impetigo
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: marmot cream
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: GoPro Stick
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: GET FAST INDEX
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: buy a fitbit
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: judi poker online
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: agen sbobet
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: www.youtube.com
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: clasipress.com
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: siegefall cheats
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: judi indonesia
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: yuri manga
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: follow my blog
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: beat-all.com
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: audiobook download
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: a
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: zee
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: faktura mal
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: zee bee junior
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: Infiintare Firma
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: catchy domain name
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: attorney
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: help site
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: good domain name
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: woolgames.com
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: Bandar Domino
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: Laci Robinett
    I found a great...
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: go pro pole
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: www.youtube.com
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: offer Activities
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: CASINO
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: auction Site
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: Dobry Ebook
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: holdem texas
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: buy Crane truck
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: More hints
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: sex
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: Guitar training
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: Asphalt roof
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: Going Listed here
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: My Web Site
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: lou ryan
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: Alisia Opel
    I found a great...
  • Response
    Response: Ackley
    I found a great...
  • Response
    Response: auction site
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: Sex web cam
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: infiintare firma
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: marketing
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: linked site
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: Genevive Dipaolo
    I found a great...
  • Response
    Response: Scott Renk
    I found a great...
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: wine around
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates
  • Response
    Response: solar power
    DiNicola Seligson & Upton - Articles (Blog) - Construction Schedules & Delay Claims -- Schedule Uses, Schedule Importance & Schedule Updates

Reader Comments (1)

Wow what a points has been described here.
Must Read, if you are into construction business.

November 25, 2013 | Unregistered CommenterIgna Webb

PostPost a New Comment

Enter your information below to add a new comment.

My response is on my own website »
Author Email (optional):
Author URL (optional):
Post:
 
Some HTML allowed: <a href="" title=""> <abbr title=""> <acronym title=""> <b> <blockquote cite=""> <code> <em> <i> <strike> <strong>